[DOWNLOAD] "Blaine Dalton v. Jerico Construction" by Supreme Court Of Utah ~ Book PDF Kindle ePub Free
eBook details
- Title: Blaine Dalton v. Jerico Construction
- Author : Supreme Court Of Utah
- Release Date : January 03, 1982
- Genre: Law,Books,Professional & Technical,
- Pages : * pages
- Size : 56 KB
Description
This is an appeal from a judgment denying plaintiff Blaine Dalton, dba C & D Construction Co., delay damages alleged to have been incurred in the performance of a construction contract. Dalton contracted with Jerico to complete work Jerico had contracted to perform under a contract with defendant S.A. Healy Co., a general contractor. The trial court held that Dalton had no right to delay damages which Jerico received from the United States Government, the party which had caused the delay. Dalton contends that the trial court erred in its construction of its subcontract with Jerico and alternatively that relief should have been granted on the basis of an oral contract or on equitable principles.